Terms and Conditions
The clients’ approval for work to commence shall be deemed a contractual agreement between the Client and Creatographics. The approval for the work can be through either an email confirming back the quote (with the quote document attached) or the quote document signed by the client.
Whereas, Creatographics is in the business of providing services on Computer based. Clients and Customers (hereinafter referred to as “customers”) and Creatographics are in the business of producing websites, graphic designs, and creative works for their customers, whether copyrighted or not (hereinafter referred to as “products” or “products”). Now, therefore, in consideration of the mutual promises, covenants, and conditions set forth herein, the parties hereto agree to the terms mentioned in this agreement or proposal.
Payment of the advance fee indicates that the client accepts these terms and conditions, and approves to commence the work.
Usage of Creatographics Services/Products: Client agrees not to use Creatographics services / products delivered for any business which is harmful to the society or children or is illegal. Further, the Client is fully responsible for all and any content published / distributed or allowed to be published / distributed through the Client’s website, whether hosted on servers owned/maintained by Creatographics or by the Client himself.
Client shall execute the best possible precautionary and security measures to restrict any illegitimate use of the services/solutions procured from Creatographics.
2 Months Free Technical Support:
Creatographics provides 2 months free technical support for following kind of issues:
a) Server-side scripting/programming errors/bugs
b) Logical Bugs/Calculation related errors/bugs
c) Connection errors/API Integration Errors
Above support is not available if the errors/bugs arise due to any external entity.
a) Server or software or application or extension downgrades or upgrades
b) Edits done in the code/scripts delivered by any external entity/person/professional
c) Operating System or Browser Version Downgrades/Upgrades
d) Any other factor which is not directly related to any deficiency at the end of Creatographics.
The above support is not available for the following kind of instances, unless otherwise specifically covered in the scope of project and/or deliverables:
a) General inquiries/questions related to particular features of the software/solution delivered.
b) Cosmetic updates and/or UI/UX updates.
c) Enhancements or modifications in the default features/functional logics of the software/solutions delivered.
Unless otherwise agreed explicitly, these 2 Months Free Technical Support is not available for following kinds of engagement/association with Creatographics:
(a) Full Time Web Designer or Developer Engagement/Hired.
(b) Creatographics Designers and/or Developers are working with the Client Team directly, where project management is being done by the Client Team.
(c) Creatographics is hired only for Installation and/or Support works and/or Quality only but not for the project development.
Photography and graphics:
Both the parties agree to abide by the following terms:
a) Unless otherwise agreed—Stock Images used for creating any banner or promotion graphic or animation are not part of the project deliverables, Client should purchase the license to use the stock images from respective 3rd parties at his/her own cost.
b) Creatographics may use stock photographs and images while creating the website. Images and graphics purchased from stock libraries are not generally included in the quote and will be invoiced separately.
c) At request of the Client – Creatographics will keep the client updated about the stock images being used and the cost involved before raising the invoice.
d) Images used by Creatographics for product demos shall not be used by the client unless the client has purchased the usage rights for those images. Client shall be fully responsible for violation of any 3rd party copyright.
e) Images delivered by Creatographics along with a bundled software/solution/script are for Demo Purpose only and shall not be used for commercial purpose. Client should contact Creatographics for more information about the price of those images if the Client wishes to use those images for commercial purpose, OR Client should replace the default images with the images owned by the Client.
Creatographics makes every effort to design pages that work flawlessly on most popular current browsers i.e., latest version of IE / FireFox / Chrome released on the date of project agreement. However, Creatographics cannot be held responsible for pages that do not display acceptably in newer versions of browsers released after pages have been designed. IE11 and older IE versions are outdated browsers and hence we don’t design with them in mind. We recommend using latest version of Chrome or Firefox instead of older versions of Microsoft Internet Explorer. Creatographics can work on improving UI/UX for older versions of Internet Explorer for an additional charge.
Search Engine Submission:
Following services are not part of the project unless agreed otherwise in writing:
a) Submission of websites on different search engines.
b) Securing good ranking of your website on different search engines.
c) Search Engine Optimization – On Page/Off Page.
Site maintenance: Unless otherwise agreed in writing, the following services will be separately billed after the website has been made live:
a) Content updates
b) Refinements and logical tweaks to the website, which were not planned/approved by client earlier.
c) Content presentation and design updates that were not planned/approved by client earlier.
After Creatographics has delivered the website to client, client is solely responsible for the content /information/ images posted on his website. If there is any error or omission by Creatographics team while uploading/posting the content/information/images on clients’ website, Creatographics will correct it if reported to Creatographics representatives.
All material supplied by the client shall remain client’s property.
Creatographics rightfully believes that this material belongs to the client and that it does not breach any copyright laws. Under no circumstances shall Creatographics be held responsible for any claims, damages, and loss of profit or reputation caused to client due to the use of material provided by the client.
Domain names booked by Creatographics on behalf of client:
Creatographics provides domain name consultancy if required. Domain names registered by Creatographics on the client‟s behalf are property of Creatographics until the client has paid for the domain booked and any fee involved.
Creatographics agrees to transfer such domains to the client or his/her agent when asked to do so, provided that all accounts have been settled.
Domains booked and owned by client are not subject to this term. This term applies only to those domains that are booked by Creatographics upon the request of the client.
Travel Time and Expenses:
Travelling time to and from the client premises is not generally included in our estimate. If a visit/travel is required for meeting, the client will bear all the expenses or as agreed by both the parties.
3rd Party Add on/services/applications: All third-party costs arising from the registration of a domain name/purchase of third-party utilities/services shall be met by the Client and are payable to Creatographics before a formal application for registration is made.
Examples of 3rd party fees are as under:
- Domain Names
- Server Space Hosting Fees
- SSL certificates.
- Backup Services
- 3rd Party APIs, if any, required by “Clients” to be integrated with the work ordered.3rd Party Add-ons/services/applications: All third-party costs arising from the registration of a domain name/purchase of third-party utilities/services shall be met by the Client and are payable to Creatographics before a formal application for registration is made. Examples of 3rd party fees are as under:3rd Party Plugins/Scripts/Applications/Software/Widgets/Services, if any, required by “Clients to be integrated with the work ordered.
- Payment Gateways Signup and Recurring Fees.
Examples of work:
Unless negotiated otherwise, Creatographics retains the right to list/display the client’s name and logo with or without work performed (Design/Development/Online Promotion) for the Client in its respective portfolios and promotion materials. This over-ride all previous agreements and NDAs signed.
The price quoted to the client is for the work agreed in the proposal document only. Should the client decide that changes are required after the project work has been initiated, then Creatographics will provide a separate quote for the additional work and may need to review the timescale for completing the project. Cost estimates and prices quoted are valid for maximum one month, unless otherwise agreed.
Mode of Payment
- Clients Based Outside India: International Wire Transfers, Credit Card/PayPal via 2Checkout payment gateway.
- Clients Based in India: UPI, NEFT, RTGS or Physical Cheques mailed to our office address.
- Payments for packages/services other than covered under ecommerce package and Mid-Size Business and Large Business Packages should be made via Wire Transfer only.
- Payment plan is agreed between the „Client‟ and Creatographics based on the milestones.
- The Payment shall be due within 14 days of the invoice date, unless specifically mentioned in the Invoice.
Full publication of the website/technical work will only take place after full payment has been received in our account, unless otherwise agreed in writing.
- Any material previously published may be removed if payment is not received. When this occurs, a minimum charge of $150 USD will be charged to have the site restored.
- Accounts that have not been settled within 14 days of the date shown on the invoice will incur a late payment charge of $100 USD or 5% of the Invoiced Amount (whichever is higher), for each week delayed.
- In case of delay in payments beyond the due date, Creatographics reserves the right to stop the work being commenced and Clients agrees to exempt Creatographics from meeting the timelines agreed.
Both the parties reserve the right to cancel the project at any stage.
- In case the project is cancelled by Client, the payments made for the project can be refunded to the client after deducting the upfront payment amount received for Initiation of the project and the other payments received against the milestones completed.
- In case the project is cancelled by Creatographics, the payments made for the project can be refunded after deducting $15 per hour for the hours spent on the work performed for the client including but not limited to the time spent on project discussion, requirements gathering, project planning & documentation, project initiation and execution. After the payments are settled between the two parties – Creatographics shall transfer to „Client‟ – all the documents, designs and scripts produced for the project.
Penalties applicable on Creatographics:
- Creatographics agrees to finish the project as per the detailed project scope agreed to, within the agreed timeline. If there is the delay in finishing the project, Creatographics agrees to the penalty of X % of the original project price for each week delay in submitting the Project for the final review to the client. If Creatographics delays project submission for the client’s final review by more than 8 weeks, the client may request project cancellation and a full refund; however, the refund amount shall not exceed the originally agreed project price (excluding the amount charged for additional requirements and change requests). Amount charged for additional requirements/change requests shall not be refunded. X% = 50/Project Duration Weeks (Calendar Weeks); X% should not exceed 4% unless otherwise explicitly agreed to.
- Penalty Amount/Refund applicable shall be adjusted against/out of the pending amount owed by the client towards Creatographics and any remaining amount shall be refunded to the client via wire transfer or PayPal or any other mode of payment as per mutual agreement.
- Once full refund has been issued, the project shall be marked cancelled and Creatographics shall be relieved from all liabilities towards the client and client shall not make any claims, objections, demands from Creatographics for any loss or damages incurred at his/her end due to the delay. Creatographics shall own all rights on the work done, designs, scripts, documents, other outputs and elements created for the project and client shall not use any of the work, scripts, designs, documents already delivered. Client shall be liable to pay full project price in case Client uses or copies any piece of the work, design, script, elements, and documents produced by Creatographics for the project.
Responsibilities applicable on Client:
Client should provide all comments, feedbacks, suggestions about the project scope during the Detailed Project Scope Documentation phase; Subsequently any changes or modifications or enhancements done to the project scope would be additionally chargeable with or without delivery timelines revision. And if there are changes which are accepted by Creatographics without additional charge, timeline should extend by the number of days required to implement those additional non-billable items.
- Client should make payments as per the agreed payment terms, else Creatographics should be exempt from meeting the timelines agreed to, and will not be liable to any kind of penalties for the delay in delivery of the project.
- Client should provide his feedback on the work submitted for their review within 24hour, if there is a delay from client side in providing feedback on the work submitted for their review, Creatographics should be exempt from meeting the timelines agreed to, and will not be liable to any kind of penalties for the delay in delivery of the project.
- If Client changes the Functional Requirement – Client understands and accepts that additional cost and working days will be added to the project, hence the project delivery timeline will need to be revised.
Delayed Response from Client Side:
Unreasonable delays from client side in providing the required feedback/information/data to finish the project shall exempt Creatographics from meeting the timelines mentioned in the quote.
In case client does not provide required details/data/information for more than 5 working days, client authorizes
Creatographics to forfeit the payments made towards this project.
In case, during the project duration, the client does not maintain communication with Creatographics for more than 10 calendar days, client agrees that the project/services shall be deemed as received and accepted by the client, and the client further authorizes Creatographics to mark the project completed and invoice the client for remaining uninvoiced amount as per the total project price agreed.
However, Client can instruct Creatographics to put project on hold provided:
- The client agrees to pay a project resumption fee of $100 or 30% of the total project price, whichever is higher. On-hold period does not exceed 1 calendar months.
- Client agrees the professionals attached to the project (Project Team Structure) may be different from originally agreed.
- Client agrees to pay this project resumption fee every time a project is being put „on-hold‟
Creatographics ensures you get right assistance to resolve issues in a timely manner. If your concerns are not entertained to your satisfaction, you can escalate critical issues to higher level of management. You may follow the below-mentioned escalation matrix to avoid any delay or discomfort in the event of dissatisfaction.
First Level Escalation:
In case of delay in project timelines or unsatisfactory response from your associated Project Manager/Business Analyst, you may escalate your case to Mr. Suman Kumar (firstname.lastname@example.org) and expect a response within next 3 working days.
If you don’t receive a satisfactory solution from any of the team members following the first level of escalation, or haven’t received a reply within 5 business days after submitting your Feedback/Query/Complaint, you may escalate your case to our CEO Mr. Vikramraja (email@example.com). Rest assured that immediate action will be taken.
Client agrees that stipulated timelines cannot be met if the project scope is changed by client once the project scope document is finalized. Client agrees not to change the requirements without extending the original agreed timelines by minimum 1 week against each change request.
Share in profits from business or sale of business: After client makes the agreed payment for the project, Creatographics will not claim share in client’s profits from business or from sale of business to some other company.
Copyright/Ownership Rights: Creatographics will retain the copyright of any material, including design, artwork, and the source code, created for the client by Creatographics. Creatographics reserves the right to retain the copyright on all material created by Creatographics unless otherwise agreed between the two parties in writing. As per the agreed terms’ client owns rights on following items:
- a) Logo/Graphics/Pictures/Images supplied by client – Yes
- b) Website Interface/PSD/Creatives/Designs – Yes, if client has ordered custom design with Exclusive Rights.
- c) Programming Files/Source Code – Yes, if the Client has ordered the project with Exclusive Rights. Client does not own the copyright/Intellectual property rights for projects being done on Single Domain License basis.
- d) If the project is being done on Single Domain License basis, Client owns the rights to use the system only on designated domains and Client should take reasonable care of the system files to restrict unauthorized access to the system scripts/source code delivered.
Ownership of Code and Intellectual Property Rights: Unless otherwise agreed, Creatographics is the owner of the source code and the intellectual property rights and reserves the right to reuse the code for other projects.
Following terms shall be applicable and obliged:
- a) Client shall not create un-authorized copies of any Themes / Software /Scripts / Designs / File / Document/Information delivered to the Client by Creatographics;
- b) Client shall not access and/or share and/or transfer any Themes / Software / Products / information /document owned by Creatographics unless authorized to do so.;
- c) Client shall not reverse engineer any software/script/application owned by Creatographics
- d) Client shall not make any Themes/ Software/Document/File/Information available to any third party in any manner, nor may Client use such works to provide services to any third party unless explicitly agreed otherwise in writing.
In the event that Client breaches any of terms specified in this clause, Client hereby authorizes any court of competent jurisdiction in India or Abroad to pass the judgment against the Client for and in the amount for each default, as provided in the afore mentioned paragraphs, together with costs of suit and the cost of attorney incurred by Creatographics for recovery of above compensation/damages from Client. This damages/compensation allowed shall be considered as interim relief toCreatographics and Creatographics shall have the liberty to claim higher amount as compensation for the direct/indirect damages and Employer may pursue criminal proceedings as well Termination of the agreement: If either party terminates this Agreement for any reason, the parties will continue to perform all of their respective obligations under this Agreement
In no event, Creatographics shall be liable to the client or any third party for any damages, including any lost profits, lost savings or other incidental, consequential or special damages arising out of the operation of or inability to operate these Web pages or website, even if Creatographics has been advised of the possibility of such damages. Despite the best efforts of Creatographics, errors in web page information may occur. At no time will Creatographics be held responsible for accidentally including erroneous information, extending beyond correcting the error.
Should Creatographics waive any of these terms on an individual basis, this shall not affect the validity of remaining clauses or commit Creatographics to waive the same clause on any other occasion.
By agreeing to these terms and conditions, your statutory rights are not affected.
Creatographics reserves the right to change or modify any of these terms or conditions at any time, but agreements signed prior to the updates in this agreement remains unaffected. Please feel free to contact us for more info/clarification about any of the terms and conditions mentioned above.
Creatographics reserves the right to amend any or all of the above policies, guidelines, and disclaimer without notification.
If you have queries or suggestions regarding our refund policies, kindly email us at firstname.lastname@example.org / +919629683501